48 CFR § 832.111-70 - 832.111-70 VA contract clauses for non-commercial purchases.

---
identifier: "/us/cfr/t48/s832.111-70"
source: "ecfr"
legal_status: "authoritative_unofficial"
title: "48 CFR § 832.111-70 - 832.111-70   VA contract clauses for non-commercial purchases."
title_number: 48
title_name: "Federal Acquisition Regulations System"
section_number: "832.111-70"
section_name: "832.111-70   VA contract clauses for non-commercial purchases."
chapter_number: 8
chapter_name: "DEPARTMENT OF VETERANS AFFAIRS"
subchapter_number: "E"
subchapter_name: "GENERAL CONTRACTING REQUIREMENTS"
part_number: "832"
part_name: "CONTRACT FINANCING"
positive_law: false
currency: "2026-04-05"
last_updated: "2026-04-05"
format_version: "1.1.0"
generator: "[email protected]"
authority: "40 U.S.C. 121(c); 41 U.S.C. 1303; 41 U.S.C. 1702; and 48 CFR 1.301 through 1.304."
regulatory_source: "73 FR 2717, Jan. 15, 2008, unless otherwise noted."
cfr_part: "832"
---


# 832.111-70 832.111-70   VA contract clauses for non-commercial purchases.

(a)(1) Insert the clause at 852.232-70, Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract does not require use of the “Network Analysis System—Critical Path Method (NAS-CPM).”

(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.

(b)(1) Insert the clause at 852.232-71, Payments Under Fixed-Price Construction Contracts (Including NAS-CPM), in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract requires use of the “Network Analysis System—Critical Path Method (NAS-CPM).”

(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.

[83 FR 49306, Oct. 1, 2018]